Indentures often contain make-whole premiums payable upon early redemption of the debt, and term B loan agreements often include "soft call" protection in the form of prepayment premiums during the early life of the loan. If the debt issuer becomes subject to a chapter 11 proceeding after the debt issuance, the question then arises as to how this payment obligation is to be treated: Does the make-whole or prepayment premium constitute unmatured interest due as a result of the debt acceleration, which would be disallowed, or is it liquidated damages?
Get your 5 Minute Fix of major projects and construction news. This issue: discover the latest cladding developments; resources construction work now caught by WA training levy; mind the gap: public transport at the urban fringe; avoid slip-ups in your payment schedule; and the availability of insolvency processes under the Corporations Act 2001 for recovering SOP debts.
Cladding update ‒ NSW
Key Points:
Principals or contractors dealing with insolvent downstream companies should ensure they can properly substantiate any counterclaims.
Usually a principal is not entitled to rely on a set-off or counterclaim to resist court proceedings to recover a debt under the Building and Construction Industry Security of Payment Act 2002 (Vic) (SOP Act). However because of the operation of section 553C of the Corporations Act, the situation is different if the claimant is in liquidation.
Insolvent subcontractor’s claim
The High Court of England & Wales considered, in respect of the delayed completion of a solar project, the appropriate end date for liquidated damages under a terminated construction contract.
It is usual and standard for a construction contract to contain a liquidated damages clause. It is also common for a termination clause to be included and it is not unusual for it to be exercised. Strangely, however, it is not clear under English law how these two concepts interact.
In a noteworthy decision to participants in the energy industry, the High Court of England & Wales examined what constitutes a valid liquidated damages clause in the event of delayed completion of a solar project. And last week in Singapore, the High Court considered the enforceability of liquidated damages provisions on termination of power purchase agreements.
On March 18, 2019, Judge Stuart M. Bernstein of the United States Bankruptcy Court for the Southern District of New York issued a decision enforcing a mortgage lender’s claim for a prepayment premium (a/k/a make-whole or yield maintenance premium) notwithstanding the lender’s prepetition acceleration of the loan due to the debtor’s default.
In Giant Eagle, Inc. v. Phar-Mor, Inc.,1 the United States Court of Appeals for the Sixth Circuit held that a lessor-claimant whose lease was rejected pursuant to section 365(a) of Title 11 of the Bankruptcy Code was entitled to a claim for future-rent damages against the debtor, even though the lessor had entered into a nearly identical substitute lease. The Court concluded that efforts to mitigate damages by the lessor would not be considered in reducing the actual damage claim when those efforts failed to reduce the actual harm suffered by the lessor.
In In re Calpine Corporation, 2007 WL 685595 (Bankr. S.D.N.Y. 2007), the Bankruptcy Court for the Southern District of New York considered the issue of whether secured creditors whose debt was being paid prior to its original maturity date were entitled to a prepayment premium.
The Court of Appeal decision in Triple Point Technology Inc v PTT Public Company Ltd turns on the wording of that particular contract, but was, in part, unexpected.
This decision does not reflect the generally held view (prior to this case) that liquidated damages will be recoverable until the point of termination at least.
Background