Imagine this: a contractor undertakes to perform certain works by a specified date, and agrees to pay liquidated damages (LDs) if it does not complete by that date (subject to any entitlement to an extension of time). The contractor, through its own fault, is late and does not complete by the specified date. In fact, the contractor is very late and, in the end, the employer terminates the contract before the works are completed (as it is entitled to do under the contract).

• The Court of Appeal has given guidance to insolvent companies about whether to commence an adjudication.
• There is an important distinction to be drawn between a company in a CVA and one in liquidation.
• Parties need to be careful when making general reservations to an adjudicator's jurisdiction.

What's it about?

The Court of Appeal has recently considered two appeals in which the interplay between the construction adjudication process and the insolvency regime was considered; Bresco Electrical Services Limited (in liquidation) v Michael J Lonsdale (Electrical) Limited (see my blog of 28 September 2018 on the TCC decision) and Cannon Corporate Limited v Primus Build Limited.

In a decision to be welcomed by ratepayers, the Court of Appeal in Rossendale Borough Council and others v. Hurstwood Properties (A) Limited and others [2019] EWCA Civ 364 has confirmed that certain types of mitigation schemes are not sufficient to pierce the corporate veil and transfer liability for business rates to the beneficiaries of those schemes.

Liability for business rates

The Court of Appeal decision in Triple Point Technology Inc v PTT Public Company Ltd turns on the wording of that particular contract, but was, in part, unexpected.

This decision does not reflect the generally held view (prior to this case) that liquidated damages will be recoverable until the point of termination at least.

Background

On 26 February 2019, HMRC launched a consultation entitled “Protecting your tax in insolvency”, on the government’s proposal to make HMRC a secondary preferential creditor for taxes paid by employees and customers (the new powers are contained in the proposed Finance Bill 2019-20).

It is little wonder why Andrew Tinkler’s removal from the Stobart Group (and subsequent court case) attracted so much media attention:

A recent English Court of Appeal judgment has resolved some doubts regarding the use of adjudication procedures in insolvency.

Last year the Technology and Construction Court (TCC) held that a company in liquidation cannot refer a dispute to adjudication in circumstances where there are claims by a company in liquidation and cross claims by the other party1.

In a consultation issued by the UK tax authority, HM Revenue & Customs (HMRC), on 26 February 2019, a change in the order of asset distribution in the insolvency of UK companies has been proposed. The amendments would newly favour certain taxes collected and held by an insolvent entity ahead of certain secured and unsecured creditors and would come into force in April 2020.