It was a painful outcome for the administrator of ARY Digital UK Limited (“ARY”) when he was found in breach of duty and liable to pay £743,750.

The case of Brewer and another (as joint liquidators of ARY Digital UK Ltd) vIqbal [2019] EWHC 182 (Ch) reminds office holders of the importance of understanding what assets they are selling, ensuring that correct marketing processes are employed and obtaining proper valuations.

How deep is the “pool of facts in which it is permissible to fish for the basis of the new cause of action” if a party wishes to benefit from the ‘relation back’ doctrine when calculating limitation periods? The Court of Appeal gives guidance on the meaning of “the same or substantially the same facts” for the purpose of CPR r 17.4(2).

Imagine this: a contractor undertakes to perform certain works by a specified date, and agrees to pay liquidated damages (LDs) if it does not complete by that date (subject to any entitlement to an extension of time). The contractor, through its own fault, is late and does not complete by the specified date. In fact, the contractor is very late and, in the end, the employer terminates the contract before the works are completed (as it is entitled to do under the contract).

• The Court of Appeal has given guidance to insolvent companies about whether to commence an adjudication.
• There is an important distinction to be drawn between a company in a CVA and one in liquidation.
• Parties need to be careful when making general reservations to an adjudicator's jurisdiction.

What's it about?

In high stakes restructurings, directors can be under significant pressure from different parts of the capital structure to take (or refrain from taking) certain actions. It is critical that the board understands whether it owes duties to members or creditors (or both). For such an important issue, the law has previously been remarkably unclear.

On 1 March 2019 the Court of Appeal handed down judgment in First City Monument Bank Plc v Zumax Nigeria Ltd [2019] EWCA Civ 294, a decision which will provide welcome clarity to those engaged in international banking and the financing of international trade.

SUMMARY

The Court of Appeal of England and Wales (“CA”) made a significant ruling on two matters affecting the powers and duties of directors of English companies.

An old friend

It is little wonder why Andrew Tinkler’s removal from the Stobart Group (and subsequent court case) attracted so much media attention:

A recent English Court of Appeal judgment has resolved some doubts regarding the use of adjudication procedures in insolvency.