Latham & Watkins operates worldwide as a limited liability partnership organized under the laws of the State of Delaware (USA) with affiliated limited liability partnerships conducting the practice in France, Hong Kong, Italy, Singapore, and the United Kingdom and as an affiliated partnership conducting the practice in Japan. Latham & Watkins operates in South Korea as a Foreign Legal Consultant Office. Latham & Watkins works in cooperation with the Law Office of Salman M. Al-Sudairi in the Kingdom of Saudi Arabia.

The court offers guidance on reversing lawful dividend payments and when directors need to take intoaccount creditors’ interests.

On 6 February 2019, the UK Court of Appeal published a judgment in BTI v. Sequana that will impact both creditors and directors of English companies.

Freezing Injunctions

Delivering on the announcement in the Autumn Budget, HMRC issued its consultation "Protecting your taxes in insolvency" on 26 February 2019. The consultation proposes legislation that will give HMRC the elevated status to secondary preferential creditor in a company's insolvency. If this is implemented, HMRC will have priority to recover certain taxes from insolvent businesses ahead of other creditors from 6 April 2020.

[2019] EWCA Civ 230

This was an appeal by the supplier of a software system against a TCC judgment dismissing its claim and ordering it to pay substantial damages on the counterclaim. The main issue of principle which arose was how to apply a clause imposing liquidated damages for delay in circumstances where the contractor or supplier never achieves completion.

It was a painful outcome for the administrator of ARY Digital UK Limited (“ARY”) when he was found in breach of duty and liable to pay £743,750.

The case of Brewer and another (as joint liquidators of ARY Digital UK Ltd) vIqbal [2019] EWHC 182 (Ch) reminds office holders of the importance of understanding what assets they are selling, ensuring that correct marketing processes are employed and obtaining proper valuations.

How deep is the “pool of facts in which it is permissible to fish for the basis of the new cause of action” if a party wishes to benefit from the ‘relation back’ doctrine when calculating limitation periods? The Court of Appeal gives guidance on the meaning of “the same or substantially the same facts” for the purpose of CPR r 17.4(2).

Imagine this: a contractor undertakes to perform certain works by a specified date, and agrees to pay liquidated damages (LDs) if it does not complete by that date (subject to any entitlement to an extension of time). The contractor, through its own fault, is late and does not complete by the specified date. In fact, the contractor is very late and, in the end, the employer terminates the contract before the works are completed (as it is entitled to do under the contract).

• The Court of Appeal has given guidance to insolvent companies about whether to commence an adjudication.
• There is an important distinction to be drawn between a company in a CVA and one in liquidation.
• Parties need to be careful when making general reservations to an adjudicator's jurisdiction.

What's it about?

The Court of Appeal has recently considered two appeals in which the interplay between the construction adjudication process and the insolvency regime was considered; Bresco Electrical Services Limited (in liquidation) v Michael J Lonsdale (Electrical) Limited (see my blog of 28 September 2018 on the TCC decision) and Cannon Corporate Limited v Primus Build Limited.