On 30 October 2014, the English High Court sanctioned the second scheme of arrangement for the APCOA group (the “Scheme”). APCOA has been one of the hottest names in the restructuring market in 2014. First, it broke new ground in relation to an “amend and extend” scheme in early 2014 when it established sufficient connection to England off the back of a change in governing law. Second, the Scheme was aggressively opposed and its sanction by the High Court was appealed to the Court of Appeal (although ultimately the appeal was withdrawn).

The High Court of England & Wales considered, in respect of the delayed completion of a solar project, the appropriate end date for liquidated damages under a terminated construction contract.

It is usual and standard for a construction contract to contain a liquidated damages clause. It is also common for a termination clause to be included and it is not unusual for it to be exercised. Strangely, however, it is not clear under English law how these two concepts interact.

Directors of ‘can pay, won‘t pay’ award debtors face the prospect of an extended stay in England should they choose to defy a receivership order granted by the English Court in aid of enforcement.

Introduction

All three institutions of the European Union have now approved the EU Preventive Restructuring Framework Directive. This is the EU's first attempt to "harmonise" insolvency laws across the Member States, that have disparate existing legislation. What does the Directive do and what will be its effect in practice?

The Directive

The UK has long-since established itself as a jurisdiction of choice for complex cross-border restructurings involving corporate groups whose principal operations are overseas.

In a noteworthy decision to participants in the energy industry, the High Court of England & Wales examined what constitutes a valid liquidated damages clause in the event of delayed completion of a solar project. And last week in Singapore, the High Court considered the enforceability of liquidated damages provisions on termination of power purchase agreements.

One of the recent hot topics in the European restructuring market has been whether the UK Courts would sanction a scheme of arrangement in relation to a foreign company, with no previous connection to the UK whatsoever, where the sole basis for establishing jurisdiction to undertake the scheme would be amending the governing law and jurisdiction clauses of the company’s principal finance documents to English law.

In a decision of interest to construction industry participants, the English Technology and Construction Court confirmed that, in some circumstances, the directors of an insolvent company may be liable in tort for the failings of that company.

It is not uncommon that, after performing works, a contractor finds out that the employer is insolvent. This may have serious consequences as the contractor will be most likely ranked behind other categories of the employer's creditors in any insolvency process. In this situation, what are the contractor’s other options?

On 4 February 2014, our client, Zlomrex International Finance S.A. (“ZIF”), completed the restructuring of its approximately €118 million senior secured high yield notes due 2014 (the “Existing High Yield Bonds”). ZIF, a company incorporated in France, is a financing vehicle for the Cognor group, one of the largest suppliers (by volume) of scrap metal, the second largest seller of semi‑finished steel products and the fifth largest seller (by volume) of finished steel products in Poland.

Judge Martin Glenn granted recognition to a UK scheme of arrangement with third-party releases that lacked full creditor consent. In re Avanti Communs. Grp., PLC, No. 18-10458, 2018 Bankr. LEXIS 1078 (Bankr. S.D.N.Y. Apr. 9, 2018). While stating that “granting third-party releases in chapter 11 cases is controversial,” Judge Glenn noted that courts will more willingly enforce third-party releases in chapter 15 cases, given the importance of comity and respect for foreign proceedings.