Welcome to this bulletin from 1 Chancery Lane's Property, Chancery and Commercial Law team.
In this edition:
The Pension Schemes Bill [HL] 2019-20 (Bill) was re-introduced before Parliament on 7 January 2020. Among its proposed amendments to the Pensions Act 2004 (Act) are new criminal offences for failing to comply with a contribution notice, avoiding employer debt, conduct risking accrued scheme benefits, an expansion of the moral hazard powers and an extension of the ‘notifiable events’ framework. The Government’s stated intention is to “ensure that those who put pension schemes in jeopardy feel the full force of the law“.
The Pension Schemes Bill promised in the Queen’s Speech has been introduced into Parliament. At nearly 200 pages the Bill is comprehensive, wide-ranging and ticks many of the boxes on the Pensions Regulator’s wish list. It substantially reflects the Bill which briefly appeared in the autumn: this time, it seems likely to make it to the statute book. The Bill as drafted has potentially far-reaching implications, if it is passed substantially in its current form.
Transactions and restructuring
Tamara Oppenheimer, Rebecca Loveridge and Samuel Rabinowitz, Fountain Court Chambers
This is an extract from the fourth edition of GIR's The Practitioner’s Guide to Global Investigations. The whole publication is available here.
35.1Introduction
Does termination of a contract before the works are complete impact an employer’s ability to recover liquidated damages? This question was recently considered by the English Court of Appeal. The answer? It depends on the terms of the contract. However, it seems that many liquidated damages provisions, including those in currently used standard form construction contracts, may not apply at all on termination of the contract, leaving employers to prove a claim for general damages for delays suffered both before and after termination.
Recently, the Court of Appeal upheld the High Court's decision in the Nortel Networks and Lehman Brothers disputes. The judgment confirms that liabilities under Financial Support Directions (FSDs) and Contribution Notices (CNs), which are issued by the Pensions Regulator, will rank ahead of almost all other claims when a company becomes insolvent. The discussions in the case focused on whether FSDs and CNs are classed as 'provable debts', expenses of the insolvency or, indeed, neither.
Where lenders rely on floating charge security to make recoveries from companies in administration, some recent cases have massively increased the potential for administration expenses to swallow up those recoveries. The more well-known cases could just be the start. So, what are the potential risks? What can lenders do in the face of the law as it currently stands? What is going to happen next?
The Nortel decisions
In a recent high profile case brought by the administrators of 20 insolvent companies in the Lehman and Nortel groups, the High Court ruled that the cost of complying with a financial support direction (“FSD”) issued after the date of the commencement of a company’s administration or liquidation by the Pensions Regulator would rank as an expense of the administration or liquidation.
In a recent opinion (Masri v Consolidated Contractors International Co. SAL and others [2009] UKHL 43) handed down in the final days of the House of Lords, their Lordships clarified a point which may be of some significance for successful claimants seeking to enforce a Court order against corporate defendants.
In a decision handed down just before the end of term, auditors have won an important House of Lords ruling limiting their liability in cases where a “one man” company is used as a vehicle for fraud. The Law Lords dismissed by a majority of three to two a negligence claim brought against an audit firm for failing to detect a massive fraud at Stone & Rolls, a trading company that fell in the late 1990s – holding that the liquidators could not bring a claim for damages when the company itself was responsible for the fraud.
Background